rcw_number stringlengths 8 12 | title stringlengths 4 590 | text stringlengths 17 193k |
|---|---|---|
60.28.040 | Tax liens—Priority of liens. | (1) Subject to subsection (5) of this section, the amount of all taxes, increases, and penalties due or to become due under Title 82 RCW, from a contractor or the contractor's successors or assignees with respect to a public improvement contract wherein the contract price is thirty-five thousand dollars or more, is a l... |
60.28.051 | Duties of disbursing officer upon completion of contract. | Upon completion of a contract, the state, county, or other municipal officer charged with the duty of disbursing or authorizing disbursement or payment of such contracts shall forthwith notify the department of revenue, the employment security department, and the department of labor and industries of the completion of ... |
60.28.060 | Duties of disbursing officer upon final acceptance of contract—Request of payment of taxes, increases, penalties, and claims. | If within thirty days after receipt of notice by the department of revenue, the employment security department, and the department of labor and industries of the completion of the contract, the amount of all taxes, increases, and penalties due from the contractor or any of his or her successors or assignees or to becom... |
60.28.080 | Delay due to litigation—Change order or force account directive—Costs—Arbitration—Termination. | (1) If any delay in issuance of notice to proceed or in construction following an award of any public construction contract is primarily caused by acts or omissions of persons or agencies other than the contractor and a preliminary, special or permanent restraining order of a court of competent jurisdiction is issued p... |
60.30.010 | Retainage. | (1) An owner, contractor, subcontractor, or supplier may withhold as retainage an amount equal to not more than five percent of the contract price of the work completed for private construction projects. Partial payment allowed under this subsection is not acceptance or approval of some of the work or a waiver of defec... |
60.30.020 | Retainage bonds—Authorized surety. | (1) In lieu of retainage, a subcontractor, supplier, or contractor may tender, and a contractor or owner must accept, a retainage bond in an amount not to exceed five percent of the moneys earned by the subcontractor, supplier, or contractor. (2) A subcontractor or contractor must provide a good and sufficient bond fro... |
60.30.030 | Application. | RCW 60.30.010 and 60.30.020 only apply to private construction projects and do not apply to public improvement contracts, as defined in RCW 60.28.011 .
[ 2023 c 373 s 3 .] |
60.32.010 | Liens authorized. | Every person performing labor for any person, company, or corporation, in the operation of any railway, canal, or transportation company, or any water, mining, or manufacturing company, sawmill, lumber or timber company, shall have a prior lien on the franchise, earnings, and on all the real and personal property of sa... |
60.32.020 | Notice of lien—Contents—Filing and serving. | No person shall be entitled to the lien given by RCW 60.32.010 , unless he or she shall, within ninety days after he or she has ceased to perform labor for such person, company, or corporation, filed for record with the county auditor of the county in which said labor was performed, or in which is located the principal... |
60.32.030 | Manner of serving notice. | Service of notice, as herein required, may be made in the same manner as summons in civil actions.
[ 1897 c 43 s 3 ; RRS s 1151.]
Service of summons in civil actions: RCW 4.28.080 . |
60.32.040 | Manner of enforcing liens. | Any such lien may be enforced within the same time and in the same manner as mechanics' liens are foreclosed.
[ 1897 c 43 s 4 ; RRS s 1152.] |
60.32.050 | Receiver or assignee to pay claims first. | Whenever a receiver or assignee is appointed for any person, company or corporation, the court shall require such receiver or assignee to pay all claims for which a lien could be filed under this chapter, before the payment of any other debts or claims, other than operating expenses.
[ 1897 c 43 s 5 ; RRS s 1153.] |
60.34.010 | Liens authorized. | Every person performing labor in the operation of any restaurant, hotel, tavern, or other place of business engaged in the selling of prepared foods or drinks, or any hotel service employee, shall have a lien on the earnings and on all the property of his or her employer used in the operation of said business to the ex... |
60.34.020 | Notice of lien—Contents—Filing and serving. | The lien claimant shall within thirty days after he or she has ceased to perform such labor, file for record with the auditor of the county in which the labor was performed a notice of claim, containing a statement of his or her demand, the name of the employer and the name of the person employing him or her, if known,... |
60.34.030 | Manner of serving notice. | Service of the notice of claim may be made in the same manner as summons in civil actions.
[ 1953 c 205 s 3 .]
Service of summons in civil actions: RCW 4.28.080 . |
60.34.040 | Manner of enforcing liens—Costs. | The lien may be enforced within the same time and in the same manner as mechanics' liens are foreclosed, when said lien is upon real property, or in the same manner as provided in chapter 60.10 RCW when the lien is upon personal property. The court may allow as part of the costs of the action the money paid for filing ... |
60.34.050 | Priority of lien. | The lien created herein shall be preferred to any encumbrance which may attach after the commencement of the labor and is also preferred to any encumbrance which may have attached previously to that time, but which was not filed or recorded so as to create constructive notice thereof prior to that time, and of which th... |
60.36.010 | Liens created. | All steamers, vessels and boats, their tackle, apparel and furniture, are liable — (1) For service rendered on board at the request of, or under contract with their respective owners, charterers, masters, agents or consignees. (2) For work done or material furnished in this state for their construction, repair or equip... |
60.36.020 | Actions to enforce liens. | Such liens may be enforced, in all cases of maritime contracts or service, by a suit in admiralty, in rem, and the law regulating proceedings in admiralty shall govern in all such suits; and in all cases of contracts or service not maritime, by a civil action in any superior court of this state as provided in RCW 60.10... |
60.36.030 | Liens for handling cargo. | All steamers, vessels, and boats, their tackle, apparel, and furniture shall be held liable at all ports and places within this state or within the jurisdiction of the courts of this state or within the jurisdiction of the courts of the United States in said state for services rendered by stevedores, longshore workers,... |
60.36.040 | Liens for handling cargo—Priority. | Demands for wages and all sums due under contracts or otherwise for the performance of all or any of the services mentioned in RCW 60.36.030 shall constitute liens upon all steamers, vessels, and boats, their tackle, apparel, and furniture, and shall have priority over all other demands save and excepting the demands m... |
60.36.050 | Liens for handling cargo—Foreclosure. | The liens hereby created may be foreclosed as provided in RCW 60.10.023 .
[ 1995 c 62 s 10 ; 1969 c 82 s 13 ; 1901 c 75 s 3 ; RRS s 1186.] |
60.36.060 | Lien for breach of contract for towing, dunnaging, stevedoring, etc. | Whenever the owner, charterer, or any person or corporation operating, managing or controlling any steamship, vessel or boat shall wilfully fail, neglect or refuse to carry out or perform any express contract or portion thereof for the towing, loading, unloading, dunnaging or stevedoring of such steamship, vessel or bo... |
60.40.010 | Lien created—Enforcement—Definition—Exception. | (1) An attorney has a lien for his or her compensation, whether specially agreed upon or implied, as hereinafter provided: (a) Upon the papers of the client, which have come into the attorney's possession in the course of his or her professional employment; (b) Upon money in the attorney's hands belonging to the client... |
60.40.020 | Proceedings to compel delivery of money or papers. | When an attorney refuses to deliver over money or papers, to a person from or for whom he or she has received them in the course of professional employment, whether in an action or not, he or she may be required by an order of the court in which an action, if any, was prosecuted, or if no action was prosecuted, then by... |
60.40.030 | Procedure when lien is claimed. | If, however, the attorney claim a lien, upon the money or papers, under the provisions of *this chapter, the court or judge may: (1) Impose as a condition of making the order, that the client give security in a form and amount to be directed, to satisfy the lien, when determined in an action; (2) summarily to inquire i... |
60.42.005 | Definitions. | The definitions in this section apply throughout this chapter unless the context clearly requires otherwise. (1) "Commercial real estate" means a fee title interest or possessory estate in real property located in this state except an interest in real property which is (a) improved with one single-family residential un... |
60.42.010 | Lien upon personal property—Effective date—Notice of claim of lien—Waiver of lien rights—Court costs, attorneys' fees, and statutory interest. | (1) The lien created under this chapter is a lien upon personal property, not upon real property. (2) A broker has a lien upon the owner's net proceeds from the disposition of commercial real estate and a lien upon the net rental proceeds from the lease of commercial real estate in the amount which the owner has agreed... |
60.42.020 | Disputed claim—Order to show cause—Hearing. | (1) An owner of commercial real estate subject to a recorded notice of claim of lien against proceeds under this chapter, who disputes the broker's claim in the notice of claim of lien against proceeds, may apply by motion to the superior court for the county where the commercial real estate, or some part thereof, is l... |
60.42.030 | Lien on net rental proceeds—Order to show cause—Hearing. | (1) If a broker has a lien on net rental proceeds pursuant to RCW 60.42.010 (2), and the broker has recorded a notice of claim of lien against proceeds and otherwise complied with the requirements of this chapter, the broker may apply by motion to the superior court for the county where the commercial real estate, or s... |
60.42.040 | Priority of lien claims. | All statutory liens, consensual liens, mortgages, deeds of trust, assignments of rents, and other encumbrances, including all advances or charges made or accruing thereunder, whether voluntary or obligatory, and all modifications, extensions, renewals, and replacements thereof, recorded prior to the recording of a noti... |
60.42.050 | Deposit made pending resolution of amounts due—Recording of receipt—Release of notice of claim of lien. | A notice of claim of lien against proceeds recorded under this chapter must be released without further act, upon the recording of a receipt showing the deposit with the superior court of the county in which the commercial real estate, or some part thereof, is located, of an amount equal to one and one-quarter times th... |
60.42.060 | County auditor or recorder—Duties—Fees. | The county auditor or recorder shall record the notice of claim of lien against proceeds, and any release thereof, in the same manner as deeds and other instruments of title are recorded under chapter 65.08 RCW. Notices of claim of lien against proceeds for registered land need not be recorded in the Torrens register. ... |
60.42.070 | Delivery of notice of claim of lien—Form—Time effective—Address. | Notices to be delivered to a party under this chapter, other than service of process as required in civil actions, shall be by service of process, or by registered or certified mail, return receipt requested, or by personal or electronic delivery and obtaining evidence of delivery in the form of a receipt or other pape... |
60.42.900 | Application. | This chapter applies to lien claims based on a commission agreement entered into on, or after, July 27, 1997.
[ 1997 c 315 s 9 .] |
60.42.901 | Short title. | This chapter may be known and cited as the commercial real estate broker lien act.
[ 1997 c 315 s 10 .] |
60.44.010 | Liens authorized. | Every operator, whether private or public, of an ambulance service or of a hospital, and every duly licensed nurse, practitioner, physician, and surgeon rendering service, or transportation and care, for any person who has received a traumatic injury and which is rendered by reason thereof shall have a lien upon any cl... |
60.44.020 | Person entitled to lien under RCW60.44.010—Notice of lien—Contents—Filing. | No person shall be entitled to the lien given by RCW 60.44.010 unless such person: (1) In any effort to enforce the lien, either attempts to enforce the lien on his or her own behalf or designates a collection agency licensed under chapter 19.16 RCW to collect on his or her behalf; (2) Discloses the person's use of lie... |
60.44.030 | Record of claims. | The county auditor shall record the claims mentioned in this chapter, which record must be indexed as deeds and other conveyances are required by law to be indexed.
[ 1999 c 233 s 6 ; 1937 c 69 s 3 ; RRS s 1209-4.]
Effective date — 1999 c 233: See note following RCW 4.28.320 . |
60.44.040 | Taking note—Effect on lien. | The taking of a promissory note or other evidence of indebtedness for any services performed, as provided in this chapter, shall not discharge the lien therefor unless expressly received as a payment for such services and so specified therein.
[ 1937 c 69 s 4 ; RRS s 1209-4.] |
60.44.050 | Settlement of damages—Effect on lien. | No settlement made by and between the patient and tort feasor and/or insurer shall discharge the lien against any money due or owing by such tort feasor or insurer to the patient or relieve the tort feasor and/or insurer from liability by reason of such lien unless such settlement also provides for the payment and disc... |
60.44.060 | Enforcement of lien—Payment as evidence—Release of lien. | (1) Such lien may be enforced by a suit at law brought by the claimant or his or her assignee within one year after the filing of such lien against the said tort feasor and/or insurer. In the event that such tort feasor and/or insurer shall have made payment or settlement on account of such injury, the fact of such pay... |
60.45.010 | Medical care to injured recipient—Recovery of cost against tort feasor or tort feasor's insurer—Lien created, filing—Payment to recipient does not discharge lien. | See RCW 74.09.180 , 43.20B.040 , and 43.20B.050 . |
60.52.010 | Liens authorized—Filing statement. | In order to secure to the owner or owners of sires payment for service, the following provisions are enacted: That every owner of a sire having a service fee, in order to have a lien upon the female served, and upon the get of any such sire, under the provisions of this chapter, for such service, shall file for record ... |
60.52.020 | Auditor's certificate—Contents—Posting. | The county auditor, upon the receipt of the statement as specified in RCW 60.52.010 , duly verified by affidavit, shall issue a certificate to the owner or owners of said sire, which shall be posted by the owner in a conspicuous place where said sire may be stationed, which certificate shall state the name, age, descri... |
60.52.030 | Statement of lien—Filing—Duration of lien. | The owner or owners of any such sire receiving such certificate, by complying with RCW 60.52.010 and 60.52.020 , shall obtain and have a lien upon the female served for the period of eighteen months from the date of service, or upon the get of any such sire for the period of one year from the date of birth of such get:... |
60.52.035 | Delivery of semen by artificial insemination procedures—Lien upon female or offspring—No filing—Duration of lien—Statement of account. | When an owner of a sire, or an owner of semen from sires, provides, for the insemination of a female, reproductively viable semen from the sire, the owner of the sire, or the owner of the semen, without satisfying the requirements of RCW 60.52.010 and 60.52.020 , upon delivery of the semen by artificial insemination pr... |
60.52.040 | Foreclosure of lien. | Liens under this chapter may be foreclosed as provided in chapter 60.10 RCW.
[ 1995 c 62 s 11 ; 1969 c 82 s 14 ; 1890 p 452 s 4 ; RRS s 3059.] |
60.52.050 | Auditor's fees. | For filing certificate, making copy of such affidavit, and the certificate of date of such filing, the clerk of record shall be entitled to the same fees as are provided by law for similar service in regard to chattel mortgages.
[ 1890 p 452 s 5 ; RRS s 3059 1/2.] |
60.56.005 | Definition of "agister." | For purposes of this chapter "agister" means a farmer, rancher, herder of cattle, livery and boarding stable keeper, veterinarian, or other person, to whom horses, mules, cattle, or sheep are entrusted for the purpose of feeding, herding, pasturing, training, caring for, or ranching.
[ 2012 c 117 s 155 ; 1993 c 53 s 1 ... |
60.56.010 | Liens created. | Any agister shall have a lien upon the horses, mules, cattle, or sheep, and upon the proceeds or accounts receivable from such animals, for such amount that may be due for the feeding, herding, pasturing, training, caring for, and ranching of the animals, and shall be authorized to retain possession of the horses, mule... |
60.56.015 | Liens perfected. | An agister who holds a lien under RCW 60.56.010 shall perfect the lien by (1) posting notice of the lien in a conspicuous location on the premises where the lienholder is keeping the animal or animals, (2) providing a copy of the posted notice to the owner of the animal or animals, and (3) providing a copy of the poste... |
60.56.018 | Potential sale of animal to which lien is attached—Notice to lienholder and potential buyer. | A party subject to a lien under RCW 60.56.010 shall notify (1) the lienholder of a potential sale of the animal or animals to which the lien is attached, (2) a potential buyer of the existence of the unsatisfied lien against the animal or animals for sale, and (3) any lienholder of record of the potential sale of the a... |
60.56.021 | Violation of RCW60.56.018—Civil action for damages—Civil fine. | A person injured by a violation of RCW 60.56.018 may bring civil action in the appropriate court of jurisdiction to recover the actual damages sustained, together with the costs of the suit, including reasonable attorney fees and any other costs associated with satisfaction of the lien. The court may, in its discretion... |
60.56.025 | Lien created for care of animal seized by law enforcement officer. | If a law enforcement officer authorizes removal of an animal pursuant to chapter 16.52 RCW, the person or entity receiving the animal and aiding in its care or restoration to health shall have a lien upon the animal for the cost of feeding, pasturing, and caring otherwise for the animal. The lien attaches on the date s... |
60.56.035 | Expiration of lien. | Any lien created by this chapter shall expire one hundred eighty days after it attaches, unless, within that period, an action to enforce the lien is filed pursuant to RCW 60.56.050 .
[ 1993 c 53 s 6 ; 1987 c 233 s 3 .] |
60.56.050 | Enforcement of lien. | Any person having a lien under the provisions of this chapter may enforce the same under chapter 60.10 RCW or, at the agister's option, by an action in any court of competent jurisdiction. If enforcement is through court proceeding, the property may be sold on execution for the purpose of satisfying the amount of the j... |
60.60.010 | Liens created. | Every person, firm, or corporation who, as a commission merchant, carrier, wharfinger, or storage warehouse operator, shall make advances for freight, transportation, wharfage, or storage upon the personal property of another, or shall carry or store such personal property, shall have a lien thereon, so long as the sam... |
60.60.020 | Livestock and perishable property—Sale of. | If said property consists of livestock, the maintenance of which at the place where kept is wasteful and expensive in proportion to the value of the animals, or consists of perishable property liable, if kept, to destruction, waste or great depreciation, the person, firm or corporation having such lien may sell the sam... |
60.60.030 | Sale of other property. | All other property upon which such charges may be unpaid, due, and a lien after the same shall have remained in store uncalled for, for a period of thirty days after such charges shall have become due, may be sold by the person or persons having a lien for the payment of such charges upon giving ten days' notice: PROVI... |
60.60.040 | Application of proceeds. | The moneys arising from sales made under the provisions of this chapter shall first be applied to the payment of the costs and expenses of the sale, and then to the payment of the lawful charges of the person or persons having a lien thereon for advances, freight, transportation, wharfage, or storage, for whose benefit... |
60.60.050 | Special contract not affected. | Nothing in this chapter contained shall be so construed as to alter or affect the terms of any special contract in writing, made by the parties as to the advances, affreightment, wharfage or storage; but when any such special contract shall have been made, its terms shall govern irrespective of this chapter.
[Code 1881... |
60.60.060 | Notice, how given. | All notices required under this chapter shall be given as is or may be by law provided in cases of sales of personal property upon execution.
[Code 1881 s 1985; 1863 p 421 s 15 ; 1860 p 288 s 15 ; RRS s 1196.]
Sale of property on execution: Chapter 6.21 RCW. |
60.64.003 | "Hotel" defined. | See RCW 19.48.010 . |
60.64.005 | Record of guests—Hotels and trailer camps. | See RCW 19.48.020 . |
60.64.007 | Liability for loss of valuables, baggage and other property. | See RCW 19.48.030 and 19.48.070 . |
60.64.010 | Lien on property of guest—"Guest" defined. | The keeper of any hotel, boarding house or lodging house, whether individual, partnership or corporation, has a lien upon, and may retain, all baggage, sample cases, and other property, lawfully in the possession of a guest, boarder, or lodger, brought upon the premises by such guest, boarder, or lodger, for the proper... |
60.64.040 | Sale—Notice—Disposition of funds. | If such lien and all such charges and moneys are not fully paid and satisfied within sixty days from the time when such charges and moneys, respectively, become due, the keeper of such hotel, inn, boarding house or lodging house, may then proceed to sell such baggage, sample cases and other property, or any part thereo... |
60.64.050 | Obtaining accommodations by fraud—Penalty. | See RCW 19.48.110 . |
60.66.010 | Lien on property of guest. | Hereafter all hotel keepers, inn keepers, lodging house keepers and boarding house keepers in this state shall have a lien upon the baggage, property, or other valuables of their guests, lodgers or boarders, brought into such hotel, inn, lodging house or boarding house by such guests, lodgers or boarders, for the prope... |
60.66.020 | Sale to satisfy lien—Notice. | Whenever any baggage, property, or other valuables which have been retained by any hotel keeper, inn keeper, lodging house keeper, or boarding house keeper, in his or her possession by virtue of the provision of RCW 60.66.010 , shall remain unredeemed for the period of three months after the same shall have been so ret... |
60.68.005 | Application of chapter. | This chapter applies only to federal tax liens and to other federal liens, notices of which under any act of congress or any regulation adopted pursuant thereto are required or permitted to be recorded in the same manner as notices of federal tax liens.
[ 1988 c 73 s 1 .] |
60.68.015 | Notice of federal liens. | (1) Notices of liens, certificates, and other notices affecting federal tax liens or other federal liens must be recorded for record in accordance with this chapter. (2) Notices of liens upon real property for obligations payable to the United States and certificates and notices affecting the liens shall be recorded in... |
60.68.025 | Certification of federal liens. | Certification of notices of liens, certificates, or other notices affecting federal liens by the United States secretary of the treasury or the secretary's delegate, or by an official or entity of the United States responsible for recording or certifying of notice of any other lien, entitles those liens to be recorded ... |
60.68.035 | Fees for recording or filing federal liens. | (1) The fee for recording a lien on real estate with the county auditor shall be as set forth in RCW 36.18.010 . (2) The fee for filing liens of personal property with the department of licensing of the state of Washington shall be as determined by the department. (3) The recording or filing officer shall bill the dist... |
60.68.045 | Tax lien index—Duties of county auditor—Uniform commercial code filing system—Department of licensing. | (1) When a notice of a tax lien is recorded under RCW 60.68.015 (2), the county auditor shall forthwith enter it in the general index showing the name and residence of the taxpayer named in the notice, the collector's serial number of the notice, the date and hour of recording, and the amount of tax and penalty assesse... |
60.68.900 | Uniform application of chapter. | This chapter shall be applied and construed to effectuate its general purpose to make uniform the law with respect to the subject of this chapter among states enacting it.
[ 1988 c 73 s 6 .] |
60.68.901 | Short title. | This chapter may be known and cited as the uniform federal lien registration act.
[ 1988 c 73 s 7 .] |
60.68.902 | Effective date—1988 c 73. | This chapter shall take effect July 1, 1988.
[ 1988 c 73 s 10 .] |
60.68.903 | Effective date—1992 c 133. | This act is necessary for the immediate preservation of the public peace, health, or safety, or support of the state government and its existing public institutions, and shall take effect July 1, 1992.
[ 1992 c 133 s 4 .] |
60.70.010 | Intent—Definitions. | (1) It is the intent of this chapter to limit the circumstances in which nonconsensual common law liens shall be recognized in this state. (2) For the purposes of this chapter: (a) "Lien" means an encumbrance on property as security for the payment of a debt; (b) "Nonconsensual common law lien" is a lien that: (i) Is n... |
60.70.020 | Real property common law liens unenforceable—Personal property common law liens limited. | Nonconsensual common law liens against real property shall not be recognized or enforceable. Nonconsensual common law liens claimed against any personal property shall not be recognized or enforceable if, at any time the lien is claimed, the claimant fails to retain actual lawfully acquired possession or exclusive cont... |
60.70.030 | No duty to accept filing of common law lien—Filing of a notice of invalid lien. | (1) No person has a duty to accept for filing or recording any claim of lien unless the lien is authorized by statute or imposed by a court having jurisdiction over property affected by the lien, nor does any person have a duty to reject for filing or recording any claim of lien, except as provided in subsection (2) of... |
60.70.040 | No duty to disclose record of common law lien. | No person has a duty to disclose an instrument of record or file that attempts to give notice of a common law lien. This section does not relieve any person of any duty which otherwise may exist to disclose a claim of lien authorized by statute or imposed by order of a court having jurisdiction over property affected b... |
60.70.050 | Immunity from liability for failure to accept filing or disclose common law lien. | A person is not liable for damages arising from a refusal to record or file or a failure to disclose any claim of a common law lien of record.
[ 1986 c 181 s 5 .] |
60.70.060 | Petition for order directing common law lien claimant to appear before court—Service of process—Filing fee—Costs and attorneys' fees. | (1) Any person whose real or personal property is subject to a recorded claim of common law lien who believes the claim of lien is invalid, may petition the superior court of the county in which the claim of lien has been recorded for an order, which may be granted ex parte, directing the lien claimant to appear before... |
60.70.070 | Claim of lien against a federal, state, or local official or employee—Performance of duties—Validity. | Any claim of lien against a federal, state, or local official or employee based on the performance or nonperformance of that official's or employee's duties shall be invalid unless accompanied by a specific order from a court of competent jurisdiction authorizing the filing of such lien or unless a specific statute aut... |
60.72.010 | Liens created—Priority—Extent—Exceptions. | Any person to whom rent may be due, his or her executors, administrators, or assigns, shall have a lien for such rent upon personal property which has been used or kept on the rented premises by the tenant, except property of third persons delivered to or left with the tenant for storage, repair, manufacture, or sale, ... |
60.72.040 | Foreclosure of lien. | Said lien may be foreclosed as provided in chapter 60.10 RCW.
[ 1995 c 62 s 12 ; 1969 c 82 s 15 ; 1917 c 165 s 2 ; RRS s 1203-2.] |
60.76.010 | Lien authorized. | Every employer who is required to pay contributions, by agreement or otherwise, into a fund of any employee benefit plan in order that his or her employee may participate therein, shall pay such contributions in the required amounts and at the stipulated time or each employee affected thereby shall have a lien on the e... |
60.76.020 | Notice of lien—Contents—Filing and serving. | The lien claimant, or his or her representative on his or her behalf, or the trustee of the fund on the claimant's behalf, within sixty days after such payment becomes due shall file for record with the auditor of the county wherein the claimant is or was employed by such employer a notice of claim, containing a statem... |
60.76.030 | Manner of serving notice. | Service of the notice of claim may be made in the same manner as summons in civil actions.
[ 1961 c 86 s 3 .] |
60.76.040 | Manner of enforcing lien—Costs. | The lien may be enforced within the same time and in the same manner as mechanics' liens are foreclosed when said lien is upon real property, or within the same time and in the same manner as chattel liens are enforced when the lien is upon personal property. The court may allow, as part of the costs of the action, the... |
60.76.050 | Priority of lien. | The lien created herein shall be preferred to any encumbrance which may attach after the contribution payments became due and is also preferred to any encumbrance which may have attached previous to that time, but which was not filed or recorded so as to create constructive notice thereof prior to that time, and of whi... |
60.80.005 | Definitions. | Unless the context clearly requires otherwise, the definitions in this section apply throughout this chapter: (1) Except as otherwise provided in this subsection (1), "charges" include: (a) All lawful charges assessed by a utility operated under chapter 35.21 , 35.67, 36.36, 36.89, 36.94, or 57.08 RCW, but not evidence... |
60.80.010 | Seller of real property responsible for satisfying lien—Closing agent's duties and liabilities—Fee. | (1) Unless otherwise stated and acknowledged in writing by the purchaser, the seller of a fee interest in real property is responsible for satisfying, upon closing, any lien provided for by RCW 35.21.290 , 35.67.200 , 36.36.045 , * 36.89.090 , or 36.94.150 . (2) No closing agent may refuse a written request by the sell... |
60.80.020 | Seller's duty to inform closing agent—Written waiver—Closing agent's duties—Utility's duties—Payment of final billing. | (1) Unless the seller and purchaser waive, in writing, the services of a closing agent in administering the disbursement of closing funds necessary to satisfy unpaid charges as charges are defined in RCW 60.80.005 , the seller shall, as a provision in a written agreement for the purchase and sale of real estate, inform... |
60.80.900 | Effective date—1996 c 43. | This act shall take effect January 1, 1997.
[ 1996 c 43 s 4 .] |
60.84.005 | Definitions. | Unless the context clearly requires otherwise, the definitions in this section apply throughout this chapter. (1) "Customer" means an individual or entity that contracts with, causes, or caused a plastic fabricator to use a die, mold, form, or pattern to manufacture, assemble, or otherwise make a plastic product. (2) "... |
60.84.010 | Plastic fabricator, molder, and person conducting a plastic fabricating business has a lien—May retain possession—Notice to customer—Foreclosure by notice and sale. | (1) A plastic fabricator, molder, and person conducting a plastic fabricating business has a lien, dependent on possession, on a die, mold, form, or pattern belonging to the customer for the amount owing from the customer for plastic fabrication work and for the value of materials used in the work. The fabricator may r... |
Subsets and Splits
No community queries yet
The top public SQL queries from the community will appear here once available.