UK stringlengths 3 2.64k | EN stringlengths 3 2.82k |
|---|---|
Угода була укладена між Урядом України і Урядом Аргентинської Республіки з метою створення сприятливих умов для реалізації права на працю членами сімей співробітників дипломатичних представництв та працівників консульських установ, акредитованих на територіях Сторін. | The Agreement was concluded between the Government of Ukraine and the Government of the Republic of Argentina for the purpose of establishing favorable conditions to enable the implementation of the right to labor by family members of employees of diplomatic representations, as well as employees of consular posts accre... |
Про ратифікацію Угоди між Урядом України і Урядом Аргентинської Республіки про працевлаштування членів сімей співро... : Закон України від 20.04.2000 № 1691-III | On Ratification of the Agreement between the Government of Ukraine and the Government of the Republic of Argent... : Law of Ukraine on April 20, 2000 № 1691-III |
Про ратифікацію Угоди між Урядом України і Урядом Аргентинської Республіки про працевлаштування членів сімей співробітників дипломатичних представництв та працівників консульських установ | On Ratification of the Agreement between the Government of Ukraine and the Government of the Republic of Argentina on Employment of Family Members of Employees of Diplomatic Representations and Consular Posts |
Про ратифікацію Угоди між Урядом України і Урядом Аргентинської Республіки про працевлаштування членів сімей співробітників дипломатичних представництв та пр... (Текст резюме від 20.04.2000) | On Ratification of the Agreement between the Government of Ukraine and the Government of the Republic of Argentina on Employment of Family Members of Employe... (Abstract text on April 20, 2000) |
Строк дії Угоди необмежений. | The Agreement was signed for an indefinite period. |
Законом ратифікується Угода між Урядом України і Урядом Аргентинської Республіки про працевлаштування членів сімей співробітників дипломатичних представництв та працівників консульських установ. | The Law ratifies the Agreement between the Government of Ukraine and the Government of the Republic of Argentina on Employment of Family Members of Employees of Diplomatic Representations and Consular Posts (hereinafter referred to as "the Agreement"). |
22 травня 2000 року | May 22, 2000 |
Ця законодавча та регулююча основа передбачає наявність: | This legislative and regulatory basis shall provide for: |
Конвенція була підписана 29 вересня 1997 року у м. Відні. | The Convention was signed on behalf of Ukraine in Vienna on September 29, 1997. |
уникати вчинення дій, що мають обґрунтовано передбачувані негативні наслідки для наступних поколінь. | avoid actions that impose reasonably predictable negative consequences on future generations. |
системи відповідного відомчого та регулюючого контролю, а також документації та звітності; | a system of appropriate departmental and regulatory control, and documentation and reporting; |
URL: https://zakon.rada.gov.ua/go/1688-14 (дата звернення: 22.03.2022) | URL: https://zakon.rada.gov.ua/go/1688-14 (date of share: March 22, 2022) |
передбачати ефективний захист окремих осіб, суспільства в цілому та навколишнього природного середовища шляхом застосування на національному рівні відповідних методів захисту, затверджених регулюючим органом, в рамках свого національного законодавства, що належним чином бере до уваги схвалені на міжнародному рівні крит... | provide for effective protection of individuals, society and the environment, by applying at the national level suitable protective methods as approved by the regulatory body, in the framework of its national legislation which has due regard to internationally endorsed criteria and standards; |
При цьому кожна Сторона зобов'язана, вживати наступні заходи: | In so doing, each Contracting Party shall take the appropriate steps to: |
враховувати біологічні, хімічні та інші ризики, що можуть бути пов'язані з поводженням з відпрацьованим паливом та радіоактивними відходами; | take into account the biological, chemical and other hazards that may be associated with spent fuel and radioactive waste management; |
забезпечити, щоб утворення радіоактивних відходів, пов'язаних з поводженням з відпрацьованим паливом, підтримувалось на мінімальному практично досяжному рівні; | ensure that the generation of radioactive waste associated with spent fuel management is kept to the minimum practically achievable level; |
Конвенцією встановлюються вимоги до проектування, будівництва та експлуатації установок для поводження з відпрацьованим паливом та радіоактивними відходами. | The Convention sets requirements to design, construction and operation of facilities for spent fuel and radioactive waste management. |
Передбачається створення законодавчої та регулюючої основи для забезпечення безпеки поводження з відпрацьованим паливом та радіоактивними відходами. | It is envisaged to establish legislative and regulatory basis to ensure the safety of spent fuel and radioactive waste management. |
системи заборони експлуатації установки для поводження з відпрацьованим паливом чи радіоактивними відходами без ліцензії; | a system of prohibition of the operation of a spent fuel or radioactive waste management without a license; |
Законом ратифікується Об'єднана конвенція про безпеку поводження з відпрацьованим паливом та про безпеку поводження з радіоактивними відходами (надалі - Конвенція). | The Law ratifies Joint Convention on the Safety of Spent Fuel Management and on the Safety of Radioactive Waste Management (hereinafter the Convention). |
відповідних національних вимог відносно безпеки та регулюючих положень з радіаційної безпеки; | the establishment of applicable national safety requirements and regulations for radiation safety; |
Конвенція застосовується до безпеки поводження з відпрацьованим паливом, що утворюється в результаті експлуатації цивільних ядерних реакторів. | This Convention shall apply to the safety of spent fuel management when the spent fuel results from the operation of civilian nuclear reactors. |
Також Конвенція застосовується до безпеки поводження з радіоактивними відходами в тих випадках, коли радіоактивні відходи утворюються в результаті цивільної діяльності. | This Convention shall also apply to the safety of radioactive waste management when the radioactive waste results from civilian applications. |
Сторони домовились вживати відповідних заходів для забезпечення належного захисту окремих осіб, суспільства в цілому та навколишнього природного середовища від радіологічних ризиків на всіх стадіях поводження з відпрацьованим паливом та радіоактивними відходами. | The Parties nave agreed to take the appropriate steps to ensure that at all stages of spent fuel and radioactive waste management, individuals, society and the environment are adequately protected against radiological hazards. |
<a href="https://zakon.rada.gov.ua/go/1688-14" target="_blank">Про ратифікацію Об'єднаної конвенції про безпеку поводження з відпрацьованим паливом та про безпеку поводження з ра... : Закон України від 20.04.2000 № 1688-III</a> | <a href="https://zakon.rada.gov.ua/go/1688-14" target="_blank">On Ratification of Joint Convention on the Safety of Spent Fuel Management and on the Safety of Radioactive Was... : Law of Ukraine on April 20, 2000 № 1688-III</a> |
чіткого розподілу обов'язків органів, що займаються різними стадіями поводження з відпрацьованим паливом та радіоактивними відходами. | a clear distribution of responsibilities of the bodies involved in the different stages of spent fuel and of radioactive waste management. |
примусових заходів для виконання чинних регулюючих положень та умов ліцензій; | the enforcement measures in order to implement current regulatory provisions and terms of the licenses; |
Про ратифікацію Об'єднаної конвенції про безпеку поводження з відпрацьованим паливом та про безпеку поводження з радіоактивними відходами : Закон України від 20.04.2000 № 1688-III // База даних «Законодавство України» / Верховна Рада України. | On Ratification of Joint Convention on the Safety of Spent Fuel Management and on the Safety of Radioactive Waste Management : Law of Ukraine on April 20, 2000 № 1688-III // Database «Legislation of Ukraine» / Verkhovna Rada of Ukraine. |
забезпечити належну увагу питанням критичності та відводу залишкового тепла, що виникає в ході поводження з відпрацьованим паливом та радіоактивним відходами; | ensure that criticality and removal of residual heat generated during spent fuel and radioactive waste management are adequately addressed; |
Про ратифікацію Об'єднаної конвенції про безпеку поводження з відпрацьованим паливом та про безпеку поводження з радіоактивними відходами (Текст резюме від 20.04.2000) | On Ratification of Joint Convention on the Safety of Spent Fuel Management and on the Safety of Radioactive Waste Management (Abstract text on April 20, 2000) |
Про ратифікацію Об'єднаної конвенції про безпеку поводження з відпрацьованим паливом та про безпеку поводження з ра... : Закон України від 20.04.2000 № 1688-III | On Ratification of Joint Convention on the Safety of Spent Fuel Management and on the Safety of Radioactive Was... : Law of Ukraine on April 20, 2000 № 1688-III |
„Про ратифікацію Об'єднаної конвенції про безпеку поводження з відпрацьованим паливом та про безпеку поводження з радіоактивними відходами" | On Ratification of Joint Convention on the Safety of Spent Fuel Management and on the Safety of Radioactive Waste Management |
системи ліцензування діяльності в галузі поводження з відпрацьованим паливом та радіоактивними відходами; | a system of licensing activity in the sphere of spent fuel and radioactive waste management activities; |
враховувати взаємозалежність різних стадій поводження з відпрацьованим паливом та радіоактивними відходами; | take into account interdependencies among the different stages in spent fuel and radioactive waste management; |
Протокол підлягає ратифікації, прийняттю або затвердженню. | The present Protocol shall be subject to ratification, acceptance or approval. |
22 травня 2007 року | May 22, 2000 |
URL: https://zakon.rada.gov.ua/go/1687-14 (дата звернення: 22.03.2022) | URL: https://zakon.rada.gov.ua/go/1687-14 (date of share: March 22, 2022) |
Ратифікаційні грамоти чи документи про прийняття або затвердження передаються на зберігання Уряду Сполучених Штатів Америки, який повідомляє усі держави, що підписали Протокол, про таку передачу. | Instruments of ratification, acceptance or approval shall be deposited with the Government of the United States of America, which shall notify all signatory States of each such deposit. |
Протокол відкритий для підписання будь-якою державою, яка підписала УСЗС-ПЗМ. | The present Protocol shall be open for signature by any State that is a signatory of the PfP SOFA. |
Згідно Протоколу вислів "Паризький Протокол" означає Протокол про статус міжнародних військових штабів, створених згідно з Північноатлантичним Договором, укладений 28 серпня 1952 року в Парижі. | According to the present Protocol, the expression "Paris Protocol" shall mean the "Protocol on the Status of International Military Headquarters set up pursuant to the North Atlantic Treaty", done in Paris on August 28, 1952. |
Відповідно до Протоколу на додаток до сфери територіальної дії Паризького Протоколу, цей Протокол буде застосовуватися на території всіх його сторін. | According to the present Protocol, in addition to the area to which the Paris Protocol applies, the present Protocol shall apply to the territory of all States Parties to the present Protocol. |
<a href="https://zakon.rada.gov.ua/go/1687-14" target="_blank">Про ратифікацію Подальшого додаткового протоколу до Угоди між державами - учасницями Північноатлантичного Договору ... : Закон України від 20.04.2000 № 1687-III</a> | <a href="https://zakon.rada.gov.ua/go/1687-14" target="_blank">On the Ratification of the Further Additional Protocol to the Agreement Among the States Parties to the North A... : Law of Ukraine on April 20, 2000 № 1687-III</a> |
Законом ратифіковано Подальший протокол до Угоди між державами-учасницями Північноатлантичного Договору та іншими державами, які беруть участь у програмі „Партнерство заради миру", щодо статусу їхніх збройних сил, підписаний 3 грудня 1999 року в м. Брюсселі. | The present Law ratified the Further Additional Protocol to the Agreement among the States Parties to the North Atlantic Treaty and the Other States Participating in the Partnership for Peace Program Regarding the Status of Their Forces that was signed in Brussels on December 3, 1995. |
Про ратифікацію Подальшого додаткового протоколу до Угоди між державами - учасницями Північноатлантичного Договору та іншими державами, які беруть участь у програмі "Партнерство заради миру", щодо статусу їхніх збройних сил : Закон України від 20.04.2000 № 1687-III // База даних «Законодавство України» / Верховна Рада ... | On the Ratification of the Further Additional Protocol to the Agreement Among the States Parties to the North Atlantic Treaty and the Other States Participating in the Partnership for Peace Program Regarding the Status of Their Forces : Law of Ukraine on April 20, 2000 № 1687-III // Database «Legislation of Ukraine» / ... |
Протоколом встановлено, що для країн-партнерів положення Паризького Протоколу вимагають вирішувати спори через Північноатлантичну раду, без звернення до будь-якої зовнішньої юрисдикції. | The present Protocol establishes that, with respect to matters involving Partner States, provisions of the Paris Protocol that provide for differences to be referred to the North Atlantic Council shall be construed to require the Parties concerned to negotiate between or among themselves without recourse to any outside... |
Про ратифікацію Подальшого додаткового протоколу до Угоди між державами - учасницями Північноатлантичного Договору ... : Закон України від 20.04.2000 № 1687-III | On the Ratification of the Further Additional Protocol to the Agreement Among the States Parties to the North A... : Law of Ukraine on April 20, 2000 № 1687-III |
Про ратифікацію Подальшого додаткового протоколу до Угоди між державами - учасницями Північноатлантичного Договору та іншими державами, які беруть участь у п... (Текст резюме від 20.04.2000) | On the Ratification of the Further Additional Protocol to the Agreement Among the States Parties to the North Atlantic Treaty and the Other States Participat... (Abstract text on April 20, 2000) |
"Угода" в будь-якому місці Паризького Протоколу означає Угоду між державами - учасницями Північноатлантичного Договору щодо статусу їхніх збройних сил, яка застосовується через Угоду між державами - учасницями Північноатлантичного Договору та іншими державами, які беруть участь у програмі Партнерство заради миру, щодо ... | The "Agreement", wherever the expression appears in the Paris Protocol, shall be construed to mean the NATO Status of Forces Agreement Among the States Parties to the North Atlantic Treaty as made applicable through the "Agreement among the States Parties to the North Atlantic Treaty and the other States Participating ... |
Вислів "УСЗС-ПЗМ" у будь-якому місці цього Протоколу означає Угоду між державами - учасницями Північноатлантичного Договору та іншими державами, які беруть участь у програмі "Партнерство заради миру", щодо статусу їхніх збройних сил. | The expression "PfP SOFA", wherever the expression appears in the present Protocol, shall mean the "Agreement among the States Parties to the North Atlantic Treaty and the other States Participating in the Partnership for Peace Program Regarding the Status of their Forces". |
„Про ратифікацію Подальшого додаткового протоколу до Угоди між державами-учасницями Північноатлантичного Договору та іншими державами, які беруть участь у програмі „Партнерство заради миру", щодо статусу їхніх збройних сил" | On the Ratification of the Further Additional Protocol to the Agreement Among the States Parties to the North Atlantic Treaty and the Other States Participating in the Partnership for Peace Program Regarding the Status of Their Forces |
- відповідні структурні підрозділи місцевих державних адміністрацій. | - the relevant structural departments of local state administrations. |
Закон: | The Law: |
URL: https://zakon.rada.gov.ua/go/1641-14 (дата звернення: 22.03.2022) | URL: https://zakon.rada.gov.ua/go/1641-14 (date of share: March 22, 2022) |
- спеціально уповноважений центральний орган виконавчої влади з питань будівництва, архітектури та житлової політики; | - a specially authorized central body of executive power in the area of construction, architecture and housing policy; |
Розмір неустойки (пені) становить: | The size of a forfeit (penalty tax) shall be the following: |
Порядок стягнення встановлює Кабінет Міністрів України. | The procedure for collecting these amounts shall be established by the Cabinet of Ministers of Ukraine. |
Якщо замовник не сплатив за виконані роботи протягом 30 календарних днів після закінчення встановленого строку платежу, підрядчик має право припинити виконання робіт, але не раніш як через 10 календарних днів після повідомлення про це замовника. | If the customer has failed to pay for completed works within 30 calendar days after the established deadline for payment expired, the contractor shall have the right to terminate the fulfillment of works, but not earlier than in ten calendar days after notifying the customer thereon. |
Положення Закону поширюються на правовідносини, що виникають між юридичними особам всіх форм власності (коштів державних та комунальних підприємств, установ та організацій за договором підряду (контрактом)), які є замовниками, підрядчиками та інвесторами у процесі будівництва, розширення, реконструкції, реставрації, ка... | Provisions of the present Law shall apply to legal relations that arise between legal entities of all types of ownership (funds of state-owned and municipal enterprises, institutions or organizations according to a contractor's agreement (contract)) who are customers, contractors and investors in the process of buildin... |
- спрямований на посилення договірної дисципліни та відповідальності за цільове та ефективне використання коштів Державного бюджету України, республіканського бюджету Автономної Республіки Крим, місцевих бюджетів, коштів державних і комунальних підприємств, установ та організацій. | - aims at strengthening contractual discipline and responsibility for targeted and efficient spending of funds provided by the State Budget of Ukraine, the republican budget of the Autonomous Republic of Crimea, local budgets, funds of state-owned and municipal enterprises, institutions and organizations. |
Сторона звільняється від майнової відповідальності, якщо вона доведе, що порушення договірних зобов'язань відбулося не з її вини. | A Party shall be exempt from property liability if it proves that contractual obligations were violated not through its fault. |
У разі недотримання умов договору підряду (контракту), підрядчик або замовник зобов'язані повідомити про це спеціально уповноважений центральний орган виконавчої влади з питань будівництва, архітектури та житлової політики, а також відповідні структурні підрозділи місцевих державних адміністрацій, які йому підзвітні та... | In case of the failure to fulfill terms and conditions of a contractor's agreement (contract), the contractor or the customer shall deliver the relevant information to a specially authorized central body of executive power in the area of construction, architecture and housing policy, as well as the relevant structural ... |
<a href="https://zakon.rada.gov.ua/go/1641-14" target="_blank">Про майнову відповідальність за порушення умов договору підряду (контракту) про виконання робіт на будівництві об'є... : Закон України від 06.04.2000 № 1641-III</a> | <a href="https://zakon.rada.gov.ua/go/1641-14" target="_blank">On Property Liability for Violating Terms and Conditions of a Contractor's Agreement (Contract) on the Fulfillme... : Law of Ukraine on April 6, 2000 № 1641-III</a> |
У разі затримки перерахування платежів більш як на 90 календарних днів підрядчик має право розірвати договір підряду (контракт) і вимагати сплати неустойки (пені) та відшкодування збитків, завданих розірванням договору підряду (контракту) в частині, не покритій неустойкою (пенею). | In the instance of delaying payments for more than 90 calendar days, the contractor shall have the right to terminate a contractor's agreement (contract) and demand payment of a forfeit (penalty tax) and compensation of damages inflicted by the termination of a contractor's agreement (contract) in the part that is not ... |
Справи у спорах між замовником і підрядчиком щодо сплати неустойки (пені) за порушення строків завершення виконання робіт (здачі в експлуатацію об'єктів) та перегляду цих строків розглядаються арбітражним судом. | Cases related to disputes between the customer and the contractor that deal with the payment of a forfeit (penalty tax) for violating deadlines for completing works (putting objects into commission) and for revising these deadlines shall be resolved by an arbitration tribunal. |
У разі недотримання цього зобов'язання сума неустойки (пені), що не була стягнена в установленому порядку з винної сторони за порушення умов договору підряду (контракту), стягується за рішенням арбітражного суду до державного бюджету як із сторони, яка не заявила ці вимоги, так і з сторони, що не виконала договірних зо... | In the instance of the failure to meet this requirement, the amount of a forfeit (penalty tax) that was not collected from the party at fault for violating terms and conditions of a contractor's agreement (contract) according to the established procedure shall be collected by the decision of an arbitration tribunal in ... |
Сторони договору підряду (контракту) зобов'язані стягувати в установленому порядку неустойку (пеню) та вимагати відшкодування збитків за порушення договірних зобов'язань, передбачених договором підряду (контракту). | Parties to a contractor's agreement (contract) shall have an obligation to collect a forfeit (penalty tax) according to the established procedure and to demand a compensation for damages for violating contractual obligations envisaged by a contractor's agreement (contract). |
Контроль за дотриманням сторонами договірних зобов'язань та вимог покладається на: | The bodies responsible for overseeing how the Parties fulfill and meet contractual obligations and requirements shall be: |
- за порушення з вини замовника строків перерахування авансів і платежів за виконані підрядчиком роботи (послуги) - розміру суми простроченого платежу, з урахуванням офіційного рівня інфляції, з розрахунку облікової ставки Національного банку України, що діяла у період, за який сплачується неустойка (пеня), збільшеної ... | - for violating deadlines for transferring advance payments and payments for works fulfilled (services provided) by the contractor through the customer's fault - the amount of the overdue payment with due consideration for the official level of inflation, that proceeds from the penalty rate of the National Bank of Ukra... |
- визначає загальні правові засади майнової відповідальності за недотримання встановлених умовами договору підряду (контракту) строків завершення виконання робіт на будівництві об'єктів та здійснення розрахунків за них; | - identifies the overall legal grounds for property liability for the failure to meet the deadlines for completing works related to the construction of objects and for making settlements for these works that were established by terms and conditions of a contractor's agreement (contract); |
Майнова відповідальність за порушення умов договору підряду (контракту) застосовується до підрядчиків і замовників, що допустили невиконання або неналежне виконання договірних зобов'язань. | Property liability for violating terms and conditions of a contractor's agreement (contract) shall be applied to contractors and customers that have allowed the failure to fulfill or improper fulfillment of contractual terms and conditions. |
- за порушення з вини підрядчика строків завершення виконання робіт (здачі в експлуатацію об'єктів) - розміру договірної ціни робіт, визначеної з урахуванням офіційного рівня інфляції, з розрахунку облікової ставки Національного банку України, що діяла у період, за який сплачується неустойка (пеня), збільшеної в 1,5 ра... | - for violating deadlines for completing works (putting objects into commission) through the contractor's fault - the amount of the contractual price for works determined with due consideration for the official level of inflation, that proceeds from the penalty rate of the National Bank of Ukraine that was effective du... |
Про майнову відповідальність за порушення умов договору підряду (контракту) про виконання робіт на будівництві об'єктів : Закон України від 06.04.2000 № 1641-III // База даних «Законодавство України» / Верховна Рада України. | On Property Liability for Violating Terms and Conditions of a Contractor's Agreement (Contract) on the Fulfillment of Works Related to the Construction of Objects : Law of Ukraine on April 6, 2000 № 1641-III // Database «Legislation of Ukraine» / Verkhovna Rada of Ukraine. |
Про майнову відповідальність за порушення умов договору підряду (контракту) про виконання робіт на будівництві об'єктів (Текст резюме від 31.03.2005) | On Property Liability for Violating Terms and Conditions of a Contractor's Agreement (Contract) on the Fulfillment of Works Related to the Construction of Ob... (Abstract text on March 31, 2005) |
Про майнову відповідальність за порушення умов договору підряду (контракту) про виконання робіт на будівництві об'є... : Закон України від 06.04.2000 № 1641-III | On Property Liability for Violating Terms and Conditions of a Contractor's Agreement (Contract) on the Fulfillme... : Law of Ukraine on April 6, 2000 № 1641-III |
Майнова відповідальність передбачає стягнення за вимогою потерпілої сторони неустойки (пені), а також відшкодування збитків у частині, не покритій неустойкою (пенею), з винної сторони. | Upon demand of the injured party, property liability shall envisage collection of a forfeit (penalty tax), as well as compensation of in the part that is not covered by the forfeit (penalty tax) at the expense of the party at fault. |
Про майнову відповідальність за порушення умов договору підряду (контракту) про виконання робіт на будівництві об'єктів | On Property Liability for Violating Terms and Conditions of a Contractor's Agreement |
13 травня 2000 року | May 13, 2000 |
Транзит небезпечних вантажів через територію України здійснюється виключно у прямому сполученні одним видом транспорту без перевантаження на інший. | Transit of dangerous cargos through the territory of Ukraine shall be conducted exclusively directly by one kind of transport without reloading to the other one. |
Якщо міжнародним договором України встановлюються інші правила перевезення небезпечних вантажів, ніж передбачені цим Законом, застосовуються правила міжнародного договору. | If the international Agreement of Ukraine sets the rules of transportation of dangerous cargos other than those envisaged by this Law, the rules of international agreement shall apply. |
URL: https://zakon.rada.gov.ua/go/1644-14 (дата звернення: 22.03.2022) | URL: https://zakon.rada.gov.ua/go/1644-14 (date of share: March 22, 2022) |
Дія Закону поширюється на: | The Law shall apply to: |
Про перевезення небезпечних вантажів | On Transportation of Dangerous Cargos |
Про перевезення небезпечних вантажів (Текст резюме від 06.04.2000) | On Transportation of Dangerous Cargos (Abstract text on April 6, 2000) |
Основними завданнями законодавства з питань перевезення небезпечних вантажів є: | Basic tasks of the legislation on transportation of dangerous cargos shall be as follows: |
В Законі висвітлені повноваження Кабінету Міністрів України, Ради міністрів Автономної Республіки Крим, спеціально уповноваженого органу виконавчої влади, центрального органу виконавчої влади в галузі транспорту, Державтоінспекції Міністерства внутрішніх справ України та місцевих державних адміністрацій та органів місц... | The Law inscribes authorities of the Cabinet of Ministers of Ukraine, the Council of Ministers of the Autonomous Republic of Crimea, the specially authorized body of executive power and central body of executive power in the sphere of transport, Derzhavtoinspectsia of the Ministry of Internal Affairs of Ukraine, local ... |
Закон визначає правові, організаційні, соціальні та економічні засади діяльності, пов'язаної з перевезенням небезпечних вантажів залізничним, морським, річковим, автомобільним та авіаційним транспортом. | The Law defines legal, organizational, social and economic principles of activity related to transportation of dangerous cargos by railway, sea, river, motor car and air transport. |
Дія Закону не поширюється на перевезення небезпечних вантажів на територіях підприємств, установ та організацій, де ці вантажі виготовляються або утворюються, використовуються або захоронюються. | The Law shall not apply to transportation of dangerous cargos on the territories of enterprises, institutions and organizations, where these cargos are produced or created, used or buried. |
<a href="https://zakon.rada.gov.ua/go/1644-14" target="_blank">Про перевезення небезпечних вантажів : Закон України від 06.04.2000 № 1644-III</a> | <a href="https://zakon.rada.gov.ua/go/1644-14" target="_blank">On Transportation of Dangerous Cargos : Law of Ukraine on April 6, 2000 № 1644-III</a> |
Стандартизації підлягають загальнотехнічні та організаційно-методичні вимоги для перевезення небезпечних вантажів і методів їх випробувань та маркування. | Subject to standardization shall be general technical and organizational methodical requirements for transportation of dangerous cargos, methods of their testing and marking. |
Про перевезення небезпечних вантажів : Закон України від 06.04.2000 № 1644-III | On Transportation of Dangerous Cargos : Law of Ukraine on April 6, 2000 № 1644-III |
Про перевезення небезпечних вантажів : Закон України від 06.04.2000 № 1644-III // База даних «Законодавство України» / Верховна Рада України. | On Transportation of Dangerous Cargos : Law of Ukraine on April 6, 2000 № 1644-III // Database «Legislation of Ukraine» / Verkhovna Rada of Ukraine. |
Умови перевезення небезпечних вантажів визначаються нормативно-правовими актами, що регулюють діяльність транспорту. | The conditions for transportation of dangerous cargos are determined by the normative legal acts which regulate transport activity. |
У разі відсутності таких актів небезпечний вантаж допускається до перевезення на умовах, встановлених за рішенням відповідних органів. | In case of absence of such acts, transportation of dangerous cargos shall be permitted under the conditions set according to the decision of respective bodies. |
Транспортні засоби, якими перевозяться небезпечні вантажі, повинні відповідати вимогам державних стандартів, безпеки, охорони праці та екології, а також у встановлених законодавством випадках мати відповідне маркування і свідоцтво про допущення до перевезення небезпечних вантажів. | Transport vehicles, which transport dangerous cargos, shall meet requirements of the state standards, safety, protection of labor and ecology, and in the cases stipulated by law shall have respective marking and certificate on permit to transportation of dangerous cargos. |
В разі дорожнього перевезення відповідність транспортних засобів, обладнання, підготовки водіїв перевіряється Державтоінспекцією Міністерства внутрішніх справ України з видачею відповідних свідоцтв про допуск до перевезення. | In case of road transportation, appropriateness of transport vehicles, equipment, skills of drivers shall be examined by Derzhavtoinspectsia of the Ministry of Internal Affairs of Ukraine and respective certificates on admission to transportation shall be issued. |
Законом наводяться права та обов'язки відправника, перевізника та одержувача під час підготовки та здійснення перевезення небезпечних вантажів. | The Law introduces rights and duties of sender, carrier and recipient during preparation and conducting transportation of dangerous cargos. |
Здоров'я і життя працівників, які беруть участь у перевезенні небезпечних вантажів, підлягають обов'язковому страхуванню від нещасного випадку на виробництві та професійного захворювання у встановленому порядку. | Health and life of employees, which participate in transportation of dangerous cargos, shall be obligatory insured against industrial accident and professional disease according to set procedure. |
- забезпечення міжнародних зобов'язань у сфері перевезення небезпечних вантажів. | ensuring international liabilities in the sphere of transportation of dangerous cargos. |
- виконання робіт і надання послуг, пов'язаних з перевезенням небезпечних вантажів; | performance of works and rendering of services related to transportation of dangerous cargos; |
- установлення прав, обов'язків і відповідальності суб'єктів перевезення небезпечних вантажів. | establishment of rights, duties and responsibility of the subjects of transportation of dangerous cargos. |
Subsets and Splits
No community queries yet
The top public SQL queries from the community will appear here once available.